Wiki Law School will soon be moving! Please update your bookmarks. Our future address is www.wikilawschool.org |
Southwest Engineering v. United States
From wikilawschool.net. Wiki Law School does not provide legal advice. For educational purposes only.
(Redirected from Southwest Engineering Co. v. United States)
Southwest Engineering v. United States | |
Court | 8th Circuit |
---|---|
Citation | 341 F.2d 998 |
Date decided | March 1, 1965 |
Facts
- Southwest Engineering Co. ="Southwest" = plaintiff = a construction contractor
- United States = the federal government = defendant
- In the 1960s, Southwest & the United States signed 4 contracts with liquidated damages clauses specifying that damages would accrue at a set daily rate for each day the project was late
- Southwest was late in completing all 4 projects
- The United States determined that Southwest owed $8,300 in liquidated damages which would be subtracted from Southwest's payments
Procedural History
- Southwest sued the United States opposing the assessment of liquidated damages.
- The United States won a summary judgment.
Issues
Is a liquidated damages clause un-enforceable if a contractor's delay in completing a construction project doesn't result in actual damages?
(The United Statement admitted that it didn't sustain damages when the 4 contracts were completed late.)Holding
No. A liquidated damages clause may be enforced even if the contractor's delay didn't result in actual damages.
Judgment
Affirmed
Rule
Judge Van Oosterhout: The amount of the liquidated damages must be reasonable to be sustained in a court of law; in this case, the aforesaid amount was indeed reasonable.
Resources